top of page

Terms and Conditions – ADY Construction

25.6.2026

Welcome to ADY Construction. These Terms and Conditions govern your use of our website and services. By accessing our website or engaging our services, you agree to be bound by these terms.

1. About ADY Construction

ADY Construction provides residential and commercial construction, renovation, refurbishment, maintenance, and related building services throughout the United Kingdom.

2. Acceptance of Terms

By using our website, requesting a quotation, or engaging our services, you acknowledge that you have read, understood, and agree to these Terms and Conditions.

3. Quotations and Estimates

All quotations provided by ADY Construction:

  • Are valid for 30 days unless otherwise stated.

  • Are based on information available at the time of preparation.

  • May be subject to change if project specifications, materials, labour requirements, or site conditions change.

  • Do not constitute a legally binding contract until accepted by both parties in writing.

4. Contracts and Project Agreements

Before work begins, a written agreement may be issued outlining:

  • Scope of work

  • Project timeline

  • Payment schedule

  • Materials and specifications

  • Any special conditions

Any changes requested after commencement may result in additional costs and revised completion dates.

5. Payment Terms

Unless otherwise agreed in writing:

  • Deposits may be required before work commences.

  • Interim payments may be due at agreed project milestones.

  • Final payment is due upon completion of the agreed works.

  • Late payments may incur interest and recovery costs permitted under applicable UK law.

ADY Construction reserves the right to suspend work where payments are overdue.

6. Customer Responsibilities

Customers agree to:

  • Provide accurate information regarding the project.

  • Ensure reasonable site access during working hours.

  • Obtain any permissions, approvals, or consents not expressly agreed to be obtained by ADY Construction.

  • Remove valuable or fragile items from work areas where appropriate.

7. Delays and Force Majeure

ADY Construction shall not be liable for delays caused by circumstances beyond our reasonable control, including but not limited to:

  • Severe weather conditions

  • Material shortages

  • Supply chain disruptions

  • Government restrictions

  • Utility failures

  • Acts of God

Project completion dates are estimates and may be adjusted where necessary.

8. Materials and Workmanship

We strive to provide high-quality workmanship and materials. Any warranties offered will be detailed within the project agreement.

Warranty coverage does not apply to:

  • Normal wear and tear

  • Customer misuse or neglect

  • Damage caused by third parties

  • Structural issues not identified prior to commencement

9. Health and Safety

ADY Construction operates in accordance with relevant health and safety legislation. Customers and site visitors must comply with any safety instructions provided during project works.

10. Intellectual Property

All website content, including text, logos, graphics, photographs, and designs, remains the property of ADY Construction unless otherwise stated.

No content may be copied, reproduced, or distributed without prior written consent.

11. Website Use

Users agree not to:

  • Use the website unlawfully.

  • Attempt to gain unauthorised access to website systems.

  • Upload malicious software or harmful content.

  • Interfere with website functionality.

We reserve the right to restrict access where misuse is identified.

12. Limitation of Liability

To the fullest extent permitted by law, ADY Construction shall not be liable for:

  • Indirect or consequential losses.

  • Loss of profits, revenue, or business opportunities.

  • Delays caused by factors outside our reasonable control.

Nothing in these terms excludes liability for death, personal injury, fraud, or any liability that cannot be excluded under UK law.

13. Privacy

Any personal information collected through our website or services is handled in accordance with our Privacy Policy and applicable data protection laws, including the UK GDPR.

14. Third-Party Links

Our website may contain links to third-party websites. We are not responsible for the content, policies, or practices of those websites.

15. Complaints

If you are dissatisfied with any aspect of our service, please contact us directly so we can attempt to resolve the issue promptly and professionally.

ADY Construction
Email: info@adyconstruction.co.uk
Phone: [Insert Phone Number]

16. Governing Law

These Terms and Conditions shall be governed by and construed in accordance with the laws of England and Wales.

Any disputes arising from these terms shall be subject to the exclusive jurisdiction of the courts of England and Wales.

17. Changes to These Terms

ADY Construction reserves the right to amend these Terms and Conditions at any time. Updated versions will be published on this website with a revised effective date.

bottom of page